Quarterly report pursuant to Section 13 or 15(d)

Commitments and Contingencies

v2.4.0.6
Commitments and Contingencies
3 Months Ended
Mar. 31, 2012
Commitments and Contingencies [Abstract]  
Commitments and Contingencies Disclosure [Text Block]
COMMITMENTS AND CONTINGENCIES
Legal Proceedings
On February 27, 2009, the Company received notice of a default termination from a customer for which the Company was performing construction services. The customer seeks reprocurement costs of approximately $6.8 million. The dispute involves the customer's assertion of its understanding of the contractual scope of work involved and the completion date of the project. The Company disputes the customer's assertion as it believes that the basis of the default arose from a delay due to the discovery of and need for remediation of previously undiscovered hazardous materials not identified by the customer during contract negotiations. In February 2010, the Company filed a motion for summary judgment as to a portion of the complaint. In March 2010, the customer filed its response. Discovery is currently ongoing. A hearing on the Company's motion is scheduled for July 1, 2012.
The Company did not record an additional accrual for this matter beyond the adjustments made to the Company's expected profit on this contract because the Company believes that the likelihood is remote that any additional liability would be incurred related to this matter. Based on the contract termination notice, the Company has adjusted its expected contract revenue and profit until such time as this contingency is resolved. The Company had claims of approximately $3.8 million outstanding with the customer as of March 31, 2012. As of March 31, 2012, the Company has not recognized any revenue or profit associated with these claims.
The Company also is involved in a variety of claims and other legal proceedings generally incidental to its normal business activities. While the outcome of any of these proceedings cannot be accurately predicted, the Company does not believe the ultimate resolution of any of these existing matters would have a material adverse effect on its financial condition or results of operations.
Commitments as a Result of Acquisitions
Related to the Company's acquisition of Quantum in the third quarter of 2010 (see Note 3), certain individuals are eligible to receive additional compensation. Total potential additional compensation is up to $1,150,000 and will be recognized as compensation expense as earned.
Related to the Company's acquisition of AEG in the third quarter of 2011 (see Note 3), the former stockholders of AEG, who are now employees of the Company, may be entitled to receive up to $5,000,000 in additional consideration if AEG meets certain financial performance milestones.